In the absence of a written agreement, the agreement signed between COUTH INDUSTRIAL MARKING SYSTEMS, S.L.U. (hereinafter COUTH) and its Customer will comprise the written order document issued by the Customer (hereinafter the Order) and the corresponding confirmation of the written Order by COUTH (hereinafter the Confirmation).
If there is a written agreement, the Order and Confirmation will form an inseparable part thereof. If there is any incompatibility between the text of the agreement and the Confirmation, the content of the latter will take full force, revoking the agreement for all content where incompatibility arises between both documents.
If an agreement must be executed in various phases and with various deliveries and each of those deliveries has to follow the working of a separate agreement – which is specified in Clause 2 below -, each of the phases or delivery milestones will be considered an individual agreement and the parties will treat it separately and independently.
The Order must be sent in writing by ordinary mail, email, fax or any other medium that provides a written record of the content of the Order.
Confirmation will be issued through a written document sent in any of the conditions valid for producing the Order. Any discrepancy between the two documents must be resolved before sending the goods, with the Confirmation being the only valid document for defining the goods to be provided and the rest of the contractual conditions in case of any difference between the content of both of them.
As an exception, COUTH may accept Orders made without meeting the requirements established in the above paragraph (for example, acceptance of a telephone order) if in those circumstances the only valid document and source of obligations for the parties is that established in the Confirmation, which must be fulfilled according to the aforementioned terms.
In no case shall any offers or quotes issued by COUTH be considered Confirmation. Furthermore, said offers or quotes will be considered invalid and therefore not accepted if the Customer does not place a firm Order through the above-mentioned channels within 60 days of the offer or quote, unless explicit reference is made in that offer.
Finally, without prejudice to the provisions in written agreements signed by COUTH with its customers, COUTH reserves the right, based on its good judgement, to reject an order from any customer without having to expressly justify that rejection.
For such purposes, the provision of the goods shall be understood as depositing them in the facilities of COUTH and the corresponding notice to the customer or, in their absence, the haulage contractor assigned, whether this notice is made by COUTH by telephone or in writing. In case of telephone notice, the existence of a notice will be presumed if thirty (30) days have elapsed since the estimated delivery date communicated by COUTH without the Customer – or their haulage contractor – having picked up the goods from the facilities of COUTH.
COUTH will never offer closed, final and/or binding delivery dates. In this regard, all delivery dates indicated by COUTH will only be approximate and communicated by COUTH in good faith and solely for the purpose of facilitating a smooth business relationship. As a result, COUTH will not assume any direct or consequential liability for any type of losses or damages arising from the delivery of goods before or after the estimated delivery date communicated in a non-binding manner.
In the event of any delay by the Customer in receiving the goods provided in the aforementioned terms, COUTH reserves the right to claim from the Customer the payment of an amount equivalent to the storage costs incurred by the demurrage of the materials from the seventh working day after the provision of the goods until the actual receipt thereof. If the delay continues for a period of more than ninety (90) days, COUTH may make use of them at its free will, without prejudice to the right of COUTH to request the payment of the storage costs indicated herein.
The price to be paid by the customer in each agreement, both individually for each item and generally in each order, will be that expressly established in the Confirmation, according to the terms of Clause 2 above. All prices are subject to the addition of the corresponding Value Added Tax rate for agreements with domestic customers, apart from in the Canary Islands.
The price shall be paid, in general, and unless otherwise agreed by the parties in writing in the terms set out in the first subparagraph of Clause 2 above, in cash and, failing that, by bank transfer made within the Sixty (60) days following the date of issuance of the corresponding invoice.
COUTHreserves the right to non-acceptance of an order in case of not reaching an agreement with the Customer regarding the payment method. Delay in the payment of the agreed price for delivering the goods will automatically accrue late payment interest set forth in Law 3/2004 of 29 December, which establishes measures to combat late payments in commercial transactions, with COUTHreserving the right to demand the payment of said late payment interest and to start any other legal actions to which it may be entitled for said delay.
he Customer will not acquire the property of the equipment (not even partially of any of its elements), and consequently the equipment remains of the property of COUTH until the moment in which the same one has been integrally paid.
Until the complete transmission of the property, COUTH will have the right to recover the possession of the equipment at any time in the event that the client is not complying, even partially, his obligations of payment assumed under the corresponding order. As Long As The equipment remains the property of COUTH, the customer will not be able to ignore or allow any kind of charge or encumbrance on it.
Goods received in defective or unsatisfactory conditions must also be communicated to COUTH in the same way and within the same time frame indicated in the above paragraph.
If the communication indicated herein is not provided, it will be understood that the goods have been received by the Customer to their satisfaction.
Goods correctly supplied and satisfactorily received by the customer shall not be returned without the prior written authorisation of COUTH.
If the return of any goods is accepted, said goods shall be consigned to “prepaid” and accompanied by a note indicating the invoice number and date together with the reason for the return.
Returns will only be accepted if all articles are in the conditions in which they were supplied, without any marking and in full condition of use for COUTH.
COUTH will guarantee their Customer the correct manufacture and supply of the goods – with a warranty covering the repair or replacement of any item – provided that such item, still being correctly installed and in normal use, has any design, material or workmanship defects.
For such purposes the warranty provided by COUTH will only take effect if the defects suffered by their goods have been detected and reported to COUTH in writing, fulfilling the following three circumstances:
Furthermore, COUTH will also provide the same warranty on repaired or replaced items for six (6) months after their actual repair or replacement.
The warranty for the repair or replacement of any item excludes transport costs, taxes or other costs associated with shipment to the centre where COUTH determines that said repair or replacement should be carried out.
The subsequent delivery of materials to be repaired or replaced will be performed in the same way and incur the same distribution of costs as the original delivery indicated in Clause 3 above.
COUTH reserves the right to recover, at its discretion and judgement, any supposedly defective product communicated in writing by the Customer which will be returned to COUTH at the Customer’s expense in order to carry out the appropriate inspections to analyse the potential defect.
For products distributed by COUTH (i.e., goods supplied to COUTH by other manufacturers), COUTH’s liability will be limited to assigning to the Customer the benefit of any warranty provided by the original manufacturer of those goods and never with conditions that go beyond the terms of the above clauses.
COUTH shall not be liable for any defect in the products resulting from any drawing, design and/or specification error provided by the Customer. Finally, in compliance with the limitation of liability and warranty mentioned in this clause, COUTH shall in no case be liable to its Customer for any damage caused to them or for any compensation that they are obliged to pay to third parties for the products supplied by COUTH, being limited, in the above terms, to the repair and/or replacement of the defective goods.
Any description and transfer of specifications, plans and indications of weights and dimensions sent by COUTH are only approximate and solely designed to provide a general idea of the products to which they refer, and do not form part of the Agreement.
All plans, descriptions and information submitted by COUTH belong to COUTH which means that COUTH is therefore the owner of all industrial property rights recognised by applicable Spanish and international law on this matter.
The Customer ensures that all products are used and adjusted by qualified and experienced personnel. If for any reason the Customer does not know how to use or adjust the products correctly, the Customer must send a written request to COUTH for more information and/or explanatory leaflets for this purpose.
The Customer shall hold COUTH fully indemnified in the event of any accident or claim by a third party that arises as a result of any negligent act or omission by the Customer.
Each and every obligation contained in these conditions shall be considered a separate obligation and executed as such, without prejudice to the non-enforceability of any other obligation.
Likewise, each and every clause contained in this document shall be fully autonomous and independent, so the cancellation of any of them by any competent authority for that purpose will not affect the validity and term of the rest, which will remain in effect and be binding between the parties.
The Agreement and the aforementioned conditions of sale for any goods sold by COUTH to any of its customers shall be governed and interpreted according to Spanish law, and both COUTH and the Customer must act in accordance with it.
In case of dispute in connection with any of the above-mentioned conditions of sale, their interpretation, execution and non-execution, the parties expressly waive their right to any other jurisdiction that may apply and submit to the Courts of San Sebastian, Spain.